CONTRACTOR/HOME-OWNER
AGREEMENT
This
agreement is hereby entered into this date,
_________________________________________,
between
________________________________________________________________________,
of
_____________________________________________________________________________
hereafter-called
OWNER,
and
____________________________________________________________________________,
of
_____________________________________________________________________________,
hereafter
called CONTRACTOR.
The
said parties, for the considerations hereinafter mentioned, hereby agree to the
following:
1. The
CONTRACTOR agrees to provide all of the material and labor required to perform
the following work:
Enter the work to be performed
2. The
OWNER hereby agrees to pay the CONTRACTOR, for the aforesaid materials and
labor, the sum of $_______________________________, in the following manner:
Enter the method and timing of
payments
3. The
CONTRACTOR agrees that the various portions of the above-described work shall
be
Completed
on or before the following dates:
Enter the dates of completion
and the
entire above-described work shall be completed no later than.
Enter the final completion
date
4. The
CONTRACTOR agrees to provide and pay for all materials, tools and equipment
required
for the
prosecution and timely completion of the work. Unless otherwise specified, all
materials
shall
be new and of good quality.
5. In
the prosecution of the work, the CONTRACTOR shall employ a sufficient number of
workers
skilled in their trades to suitably perform the work.
6. All
changes and deviations in the work ordered by the OWNER must be in writing, the
contract
sum
being increased or decreased accordingly by the CONTRACTOR. Any claims for
increases in
the
cost of the work must be presented by the CONTRACTOR to the OWNER in writing,
and
written
approval of the OWNER shall be obtained by the CONTRACTOR before proceeding
with the ordered change or revision.
7. The
OWNER, Owner's representative and public authorities shall at all times have
access to
the
work.
8. The
CONTRACTOR agrees to re-execute any work, which does not conform to the drawings
and
specifications, warrants the work performed, and agrees to remedy any defects
resulting, from
faulty
materials or workmanship, which shall become evident during a period of one
year after
completion
of the work.
9. The
OWNER agrees to maintain full insurance on the above-described work during the
progress of the work, in OWNER'S name and that of the CONTRACTOR.
10. In
the event, the CONTRACTOR is delayed in the prosecution of the work by acts of
God, fire,
flood
or any other unavoidable casualties; or by labor strikes, late delivery of
materials; or by
neglect
of the OWNER; the time for completion of the work shall be extended for the
same period
as the
delay occasioned by any of the aforementioned causes.
11. In
the event, the work is delayed due to neglect of the CONTRACTOR, the CONTRACTOR
agrees
to pay the OWNER the sum of $_________________ per _____________ as liquidated
damages
until such time as the work is completed.
12. The
CONTRACTOR agrees to obtain insurance to protect CONTRACTOR against claims for
property damage, bodily injury or death due to CONTRACTOR'S performance of this agreement.
13.
Neither the OWNER or CONTRACTOR shall have the right to assign any rights or
interest
occurring
under this agreement without the written consent of the other, nor shall the
CONTRACTOR assign any sums due, or to become due, to the CONTRACTOR under the
provisions of this agreement.
14.
This agreement shall be interpreted under laws of the State of
_________________.
15.
Attorney's fees and court costs shall be paid by the defendant in the event
that judgment must
be, and
is, obtained to enforce this agreement or any breach thereof.
IN
WITNESS WHEREOF, the parties hereto set their hands and seals the day and year
written above.
______________________________________________________________________
OWNER SIGNATURE
______________________________________________________________________
CONTRACTOR SIGNATURE
No comments:
Post a Comment